Supplier terms and conditions

In this agreement:

Business Day means a day that is not a Saturday, Sunday, or public holiday in the State of South Australia.

Confidential Information means any documentation or information of a confidential nature supplied by either of the parties to the other in connection with this agreement and includes all scientific, technical, manufacturing, performance, sales, financial, commercial, contractual or marketing information possessed by each party, but specifically excludes any documentation or information which has been previously published or otherwise disclosed to the general public or is required to be disclosed by Law.

Existing Conditions means the conditions as described in clause 8, a summary and updates of which is detailed on the Government of South Australia website: https://www.legislation.sa.gov.au/legislation

Force Majeure Event means an unforeseeable and unknown event occurring after the date of this agreement beyond the reasonable control of the parties which precludes a party from performing on time an obligation under this agreement. Such circumstances include:

1. acts of God, lightning strikes, earthquakes, floods, storms, explosions, fires, and any natural disaster; and
2. acts of war, acts of public enemies, terrorism, riots, civil commotion, malicious damage, sabotage and revolution;
3. a pandemic is declared by a Governmental Agency and measures are implemented by the Government Agency to address the pandemic; and/or
4. a suspension or termination of services or works is necessitated by legislative requirement or is ordered by a Governmental Agency;

but does not include any event or circumstance which the Provider ought to have reasonably foreseen from or as a result of the Existing Conditions.

Governmental Agency means any government or any government, semi-governmental, administrative, fiscal, or judicial body, department, commission, authority, tribunal, agency, or entity including any self-regulatory organisation established under statute or any stock exchange.

Intellectual Property means all rights conferred by statute, common law, or equity in relation to patents, inventions, registered and unregistered designs, registered and unregistered trademarks, trade names, logos and get up, confidential information, copyright and moral rights and all other rights resulting from intellectual activity in the industrial, scientific, literary, or artistic fields.

Product means the goods, works, or services the subject of the Purchase Order.

Provider means the contractor, consultant or supplier engaged by the Council to supply and deliver goods, undertake works or provide services as specified in the Purchase Order.

Purchase Order means the purchase order issued by the Council that these Terms and Conditions are attached to.

Terms and Conditions mean these Terms and Conditions.

Variation means any change in the Product specified in the Purchase Order, including:

1. any increase of, decrease in, or omission from such Product;
2. any changes in the character, specifications, quality, scope, origin and/or the materials for any such Product; or
3. any additional supply of such Product.

Warranty Period means the warrant period specified in the Purchase Order.

Expressions used in the Purchase Order have the same meaning in these Terms and Conditions.

In this document, unless the context otherwise requires:

2.1. a reference to this agreement means the Purchase Order and the Terms and Conditions;

2.2. a reference to a party includes its executors, administrators, successors and permitted assigns;

2.3. words importing persons shall include individuals, partnerships, bodies corporate or unincorporated;

2.4. a reference to legislation includes any amendment to it, any legislation substituted for it, and any subordinate legislation made under it.

This agreement:

3.1.  applies to the Product provided by the Provider to the Council and the Provider is deemed to have read and agreed to the Purchase Order and Terms and Conditions prior to filling any order for the Product; and

3.2.  prevails over the Provider’s terms and conditions of sale or any other documents provided by the Provider.

The Provider agrees to supply the Product and the Council agrees to purchase the Product on the terms of this agreement.

5.1.  The Provider must provide the Product on or before the date/s specified in the Purchase Order.

5.2.  Unless otherwise specified in this Agreement, “delivery” occurs as soon as the Product is:

5.2.1.  off-loaded at the delivery address specified in the Purchase Order; and

5.2.2.  inspected by the Council and accepted as being in accordance with this agreement

5.3.  Title to and property in the Product passes to the Council on delivery of the Product.

5.4.  Risk in the Product passes on delivery of the Product

5.5.  No liability to pay for the Product arises until delivery.

Unless otherwise specified in the Purchase Order, the Council must pay the price specified in the Purchase Order by electronic funds transfer within thirty (30) days from receipt of a correctly rendered tax invoice from the Provider. The Council maintains full discretion to pay the Provider at any time within the thirty (30) days.

The invoice cannot be issued until after the Product has been provided.

Invoices must be emailed directly by the Provider to accountspayable@onkaparinga.sa.gov.au and include the following:

• Contractor details (name, address, contact details)
• ABN (where applicable)
• Addressed to ‘City of Onkaparinga’
• Invoice date (date when Goods or Services supplied/completed)
• The word ‘Invoice’
• Quantity and description of Goods or Services provided
• The price and GST components
• EFT (electronic funds transfer) details
• Purchase Order or Contract reference (where applicable)

The Provider must:

7.1.  deliver the Product in a professional and competent manner with due care, skill and diligence and within the timeframe specified in the Purchase Order;

7.2.2  comply fully and promptly at its own cost with all laws, applicable standards, codes of practice, by-laws, orders and regulations at present or in the future relating to the provision of the Product and with all requirements, notices or orders in respect of anything affected by the provision of the Product;

7.3.  provide at its own cost all supervision, labour, materials plant, tools and equipment, transport and temporary works required for the provision of the Product;

7.4.  be responsible for the care, storage and protection of unfixed items, items provided to the Provider by the Council, and items brought onto the relevant site by any sub-contractors; and

7.5.  provide, erect and maintain all barricades, guards, fences, signs, lighting and temporary roadways and footpaths necessary for the protection of the Product, other property and for the safety and convenience of the public in accordance with accepted Standards or Codes of Practice and shall remove them when no longer required.

8.1.  The Provider warrants that the Product will:

8.1.1.  consist of materials/products that are of good merchantable quality and fit for their purpose;

8.1.2.  consist of new materials, unless otherwise notified in writing by the Provider;

8.1.3.  conform with the description and the Specifications in the Purchase Order; and

8.1.4.  throughout the Warranty Period, operate in accordance with any specifications set out in the Purchase Order, and otherwise in accordance with the operation of similar products.

8.2.  If the Product is found to be defective or does not comply with clauses 8.1.1 to 8.1.4 and the Council notifies the Provider of the defect during the Warranty Period, the Provider must, at its own cost, promptly replace the Product and deliver it to the Council, or promptly rectify any defects in the Product.

8.3.  Failing rectification by the Provider, the Council may rectify defects at the cost of the Provider.

8.4.  The Provider:

8.4.1.  The Provider warrants to the Council that it has not relied on any advice or statements by the Council regarding the Existing Conditions and has taken appropriate advice in respect of the Existing Conditions or chosen not to seek or receive such advice.

9.1.  General

No Variation invalidates this agreement.

9.2.  No unauthorised Variation

9.2.1.  The Provider must not, and is not authorised to, make any Variation of the Product except:

a) a Variation instructed by the Council; and/or

b) a Variation requested by the Provider, which has been approved by the Council.

9.2.2.  Variations by the Provider arising from, or related to the Existing Conditions which were, or ought to have been, reasonably foreseen as at the date of receipt of a Purchase Order from the Council are not permitted.

9.3.  Execute Variations

The Provider must provide any Variation instructed by the Council.

9.4.  Variations in Writing

All Variations must be documented in writing and must be signed by a representative of both the Council and the Provider.

9.5.  Adjustment of Price

For the purpose of any adjustment to the price for a Variation:

9.5.1.  if practicable, the value of a Variation must be agreed by the Provider and the Council before the Provider commences to execute the Variation; or

9.5.2.  if the value of the Variation is not agreed by the Provider and the Council, the value must be determined by the Council by application of rates accepted by the Council; and

9.5.3.  if the Council gives the Provider a written instruction that a matter is so urgent that the Provider should proceed with the Variation before it is valued, the Provider may proceed with the Variation and the Council and the Provider will then jointly negotiate a reasonable value for the Variation.

A Variation must be valued as soon as practicable, and the Provider must promptly and diligently supply to the Council all relevant information to the valuation.

10.1.  Extension

10.1.1.  If the provision of the Product is delayed by a cause beyond the control of the Provider, the Provider may, subject to clauses 10.1.2 and 10.1.3, request a fair and reasonable extension of the time for the provision of the Product.

10.1.2.  Any request by the Provider for an extension must be in writing and made within seven days after the commencement of the delay and must state with particularity the cause of the delay, and include an estimate (if practicable) of the extent or likely extent of the delay in providing the Product.

10.1.3.  For the avoidance of doubt, the Provider is not entitled to an extension of time for any delays or disruptions arising from the Existing Conditions which were, or ought to have been, reasonably foreseen as at the date of receipt of a Purchase Order from the Council.

10.2.  Conditions precedent

The Provider is entitled to a time extension only if the Provider took reasonable steps to minimise the delay.

10.3.  Council’s determination

The Council must determine what (if any) fair and reasonable extension of time should be allowed to the Provider in respect of each request and must give written notice of every such determination to the Provider, and the date and time for the provision of the Product must be extended accordingly.

10.4.  Documentation

All extensions of time must be in writing and must be signed by a representative of both the Council and the Provider.

10.5.  No costs or damages

The Provider accepts the risk of all costs, losses and expenses incurred because of a delay in the provision of the Product. The Provider’s sole remedy for such a delay is an extension of time approved by the Council under this clause. No costs or damages are payable by the Council in respect of such a delay.

11.1.  The Provider must maintain all insurances reasonably required by the Council including:

a) public and product liability insurance for the amount of $20,000,000 until the completion of the works (includes the defects liability period).

b) professional indemnity insurance to the value of $5 million for a period of seven (7) years following the provision of the services.

11.2.  The Provider must provide certificates of currency in respect of the Provider’s insurances to the Council upon request.

If applicable:

12.1.  the Provider must comply with the Work Health and Safety Act 2012, any regulations made under it and any associated policies adopted by the Council, and must ensure that its employees and contractors comply with all regulations, notices and codes of practice having application to this agreement;

12.2.  the Provider must comply with the Return to Work Act 2014 (SA) and any regulations made under it;

12.3.  the Provider must comply with all reasonable directions and procedures relating to security and work health and safety as required by the Council; and

12.4.  the Provider must immediately notify the Council of any incident or accident arising from the performance of this agreement, including any incident or accident involving the public.

The Provider must indemnify the Council against all actions, proceedings, claims, demands, charges, penalties, expenses and all other liabilities arising from or in relation to the performance or non performance of any of the Provider’s obligations under this agreement. This indemnity is reduced by the extent to which the Council contributes to the event giving rise to the claim for the indemnity.

14.1.  If a Force Majeure Event causes delay or failure by a party to perform its obligations under this agreement:

14.1.1.  neither party is liable for such delay or failure; and

14.1.2.  all obligations of a party under this agreement are suspended until the Force Majeure Event ceases to apply.

14.2.  A party which is, by reason of a Force Majeure Event, unable to perform any obligation or condition required by this agreement must:

14.2.1.  notify the other party as soon as possible giving:

14.2.1.1. reasonably full particulars of the Force Majeure Event;

14.2.1.2.  the date of commencement of the Force Majeure Event and an estimate of the time required to enable it to resume full performance of its obligations; and

14.2.1.3.  where possible, the means proposed to be adopted to remedy or abate the Force Majeure Event;

14.2.2.  use all reasonable diligence and employ all reasonable   means to remedy or abate the Force Majeure Event as soon as possible;

14.2.3.  resume performance as soon as possible after termination of the Force Majeure Event or after the Force Majeure Event abates to an extent which permits resumption of performance;

14.2.4.  Notify the other party when the Force Majeure Event terminates or abates to an extent which permits resumption of performance; and

14.2.5.  Notify the other party when resumption of performance occurs.

14.3.  If a delay or failure under this clause exceeds sixty (60) days, the Council may immediately terminate this agreement by written notice to the Provider (Termination Date).

14.4.  In the event of the Council terminating this agreement pursuant to clause 14.3:

14.4.1.  The Council remains liable to pay the Provider any unpaid invoice already issued to the Council; and

14.4.2.  Within twenty (20) Business Days of the Termination Date the Provider must give the Council a final progress claim for money owing up to and including the Termination Date and not the subject of a prior progress claim.

14.5.  The Council will not otherwise be liable to the Provider for any cost, loss, expense, or damage incurred by the Provider in connection with the exercise by the Council of its rights under clause 14.3 including, without limitation, any claim relating to loss of anticipated profits or unperformed works (if relevant).

15.1.  The Council may immediately terminate this agreement by giving notice to the Provider if the Provider:

15.1.1.  becomes an externally administered body corporate or an insolvent under administration.

15.1.2.  ceases to carry on business or becomes otherwise unable to perform its obligations under this agreement; or

15.1.3.  breaches a material provision of this agreement and fails to remedy the breach within a specified reasonable time after receiving notice requiring it to do so.

15.1.4.  Termination of this agreement under this clause does not affect any accrued rights or remedies of either party.

16.1.  Each party agrees that it will not use any Confidential Information of the other party or allow any Confidential Information of the other party to be used for any purpose, except for the purposes of and in the matter contemplated by this agreement, and agrees that it will:

16.1.1.  keep confidential;

16.1.2.  take reasonable steps to ensure that the party’s officers and employees to not disclose to a third party;

16.1.3.  maintain proper and secure custody of; and

16.1.4. not use or reproduce in any form,

any Confidential Information belonging to the other party.  Any departure from a party’s obligations pursuant to this clause may only be with the written consent of the other party or as required by law or the terms of this agreement.

16.2.  The Provider consents to any disclosures made as a result of the Council complying with its obligations under the Freedom of Information Act 1991 (SA) (FOI Act), subject to any legally required consultation.

16.3.  Subject to clause 16, for the purposes of the FOI Act, the terms specified confidential in the Purchase Order are confidential. 

The Provider must keep the Council fully and regularly informed as to all matters relating to the Product and must provide to the Council any information reasonably requested by the Council for the purposes of monitoring the performance of the Provider’s obligations under this agreement.

All disputes or differences between the Council and the Provider must be referred to an arbitrator, agreed by the parties or in the absence of agreement appointed by the Chairperson for the time being of the South Australian Chapter of the Institute of Arbitrators and Mediators Australia.

This agreement does not create a relationship of employment, agency, or partnership between the parties.

20.1.  Special conditions

If there is an inconsistency between a special condition set out in the Purchase Order and the rest of this Agreement, the special condition governs to the extent of the inconsistency.

2.2.  Alteration

This agreement may be altered only in writing signed by each party.

20.3.  Assignment (Goods Only)

The Provider must not assign this agreement or any right under it without the prior written consent of the Council.

In any application for such consent, the Provider must provide all information required by the Council, including evidence that the proposed assignee is capable of providing the Product.

20.4.  Assignment (Works Only)

The Provider must not assign this agreement or any right or obligation under it without the prior written consent of the Council, which may be granted or withheld in the Council’s absolute discretion.

20.5.  Waiver

A waiver of a provision of or right under this agreement must be in writing signed by the party giving the waiver and is effective only to the extent set out in the written waiver.

20.6.  Exercise of power

The failure, delay, relaxation or indulgence by a party in exercising a power or right under this agreement is not a waiver of that power or right.

An exercise of a power or right under this agreement does not preclude a further exercise of it or the exercise of another right or power.

20.7.  Survival

Each indemnity, obligation of confidence and other term capable of taking effect after the expiration or termination of this agreement, remains in force after the expiration or termination of this agreement.

20.8.  Governing law

This agreement is governed by the law in South Australia.

The parties irrevocably submit to the exclusive jurisdiction of the courts in South Australia.

20.9.  Ombudsman

The Provider acknowledges that the Ombudsman Act 1972 (SA) empowers the Ombudsman to investigate matters in the public interest.  The Provider must ensure compliance with all obligations arising under that or any other legislation, as regards this agreement. 

20.10.  ICAC

The Provider acknowledges and agrees that by entering into this agreement with the Council the Provider will be considered to be a public officer for the purposes of the Independent Commissioner Against Corruption Act, 2012 (SA) (ICAC ACT) and is obliged to comply with the ICAC Act and the Directions and Guidelines issued pursuant to the ICAC Act, as regards this agreement.

20.11.  Working with Children and Police Checks

The Provider must comply with all laws relating to working with children, including the Child Safety (Prohibited Persons) Act 2016 (SA) (CSPP Act).

The Provider must ensure that any person engaged in prescribed child related work (as defined in the CSPP Act) in connection with the Product holds a current Working with Children Check (WWCC) issued in South Australia and is not a prohibited person.

Council may, acting reasonably and having regard to the nature of the Product, require that the Provider’s personnel (including subcontractors) hold a current Working with Children Check or a current Police Check (National Police Certificate or equivalent).

If requested by Council, the Provider will provide evidence of a current Working with Children Check or current Police Check for any person employed by the Provider or performing work on behalf of the Provider.

The Provider must immediately notify Council if it becomes aware that any relevant personnel:

• do not hold, or cease to hold, a required Working with Children or Police Check; or
• become a Prohibited Person under the CSPP Act; or
• are charged with or convicted of an offence that a reasonable person would consider relevant to their role in providing the Product or to the safety of children, vulnerable persons or the public.

Council may, acting reasonably, direct the Provider to remove any personnel from performing the Product, or from Council premises or systems, where:

• this clause is not complied with; or
• Council reasonably considers, based on information from a WWCC, Police Check or other lawful source, that the person’s continued involvement presents an unacceptable risk to the safety of children, vulnerable persons, Council staff, the public or to Council’s lawful operations or reputation.

The Provider must disclose any relevant criminal history and any ongoing or pending legal proceedings that a reasonable person would consider may affect Council’s reputation or be inconsistent with Council’s values or statutory obligations. Without limiting this clause, relevant matter may include:

• serious criminal convictions or current charges, particularly those involving dishonesty, violence, child safety, discrimination, harassment, or public order; or
• regulatory or disciplinary findings relating to the conduct of the individual or organisation or its key personnel.

Failure to comply with this clause is a material breach of this agreement. Without limiting any other rights, Council may:

• suspend performance of all or part of the Product affected by the non-compliance until it is remedied to Council’s reasonable satisfaction; and/or
• terminate this agreement immediately by written notice if the Provider fails to remedy the non-compliance within a reasonable time stated in a notice from Council, or if there is serious or repeated non-compliance with this clause.